Terms of Service

Acceptance of Terms

By accessing and using the website and services of Concrete Contractors of Cleburne (“Company,” “we,” “our,” or “us”), you accept and agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our website or services.

Services

Concrete Contractors of Cleburne provides commercial concrete construction services including but not limited to:

• Commercial slabs on grade
• Tilt-wall panel construction
• Parking lot construction and paving
• Structural concrete
• Concrete foundations
• Flatwork and finishing
• Concrete repairs and restoration
• Related concrete construction services

All services are subject to availability, project scope, and execution of appropriate contracts and agreements.

Estimates and Quotes

Any estimates or quotes provided by the Company are preliminary and subject to change based on:

• Detailed site assessment and project requirements
• Material costs and availability
• Labor requirements and scheduling
• Site conditions and accessibility
• Regulatory requirements and permitting

Estimates are valid for 30 days unless otherwise stated. Final pricing will be confirmed in writing before work commences.

Project Agreements

All construction projects require a signed contract or agreement detailing:

• Scope of work and project specifications
• Project timeline and milestones
• Payment terms and schedule
• Material specifications
• Warranty and guarantee terms
• Change order procedures
• Insurance and liability provisions

Payment Terms

Unless otherwise specified in a project contract:

• Deposits may be required before work commences
• Progress payments will be invoiced according to project milestones
• Final payment is due upon project completion and acceptance
• Late payments may incur interest charges as permitted by law
• Liens may be filed for non-payment as permitted by Texas law

Warranties and Guarantees

The Company warrants that all work will be performed in a professional and workmanlike manner in accordance with industry standards. Specific warranty terms will be outlined in individual project contracts. Warranties do not cover:

• Normal wear and tear
• Damage caused by improper use or maintenance
• Acts of nature or force majeure events
• Modifications or repairs by third parties
• Failure to follow maintenance recommendations

Limitation of Liability

To the maximum extent permitted by law, the Company shall not be liable for any indirect, incidental, special, consequential, or punitive damages, including but not limited to loss of profits, revenue, data, or use, arising out of or related to our services.

Our total liability for any claims arising from our services shall not exceed the total amount paid by the client for the specific project giving rise to the claim.

Insurance and Indemnification

The Company maintains appropriate commercial general liability insurance and workers' compensation coverage. Clients may be required to provide proof of insurance for certain projects.

Clients agree to indemnify and hold harmless the Company from any claims, damages, or expenses arising from client-provided materials, site conditions not disclosed to the Company, or client actions that interfere with project execution.

Website Use

You agree to use our website only for lawful purposes and in a manner that does not infringe the rights of, or restrict or inhibit the use of this website by any third party. You must not:

• Transmit any unlawful, harmful, or objectionable content
• Attempt to gain unauthorized access to our systems
• Interfere with or disrupt our website or servers
• Use automated systems to access or scrape our website
• Violate any applicable laws or regulations

Intellectual Property

All content on this website, including text, graphics, logos, images, and software, is the property of Concrete Contractors of Cleburne or its licensors and is protected by copyright, trademark, and other intellectual property laws.

You may not reproduce, distribute, modify, or create derivative works from our content without express written permission.

Force Majeure

The Company shall not be liable for any failure or delay in performance due to circumstances beyond our reasonable control, including but not limited to:

• Acts of God, weather conditions, or natural disasters
• Labor disputes or shortages
• Material shortages or supply chain disruptions
• Government actions or regulations
• Pandemics or public health emergencies

Governing Law and Jurisdiction

These Terms of Service shall be governed by and construed in accordance with the laws of the State of Texas, without regard to its conflict of law provisions.

Any disputes arising from these terms or our services shall be subject to the exclusive jurisdiction of the courts located in Johnson County, Texas.

Changes to Terms

We reserve the right to modify these Terms of Service at any time. Changes will be effective immediately upon posting to this website. Your continued use of our website or services after changes are posted constitutes acceptance of the modified terms.

Severability

If any provision of these Terms of Service is found to be unenforceable or invalid, that provision shall be limited or eliminated to the minimum extent necessary so that these terms shall otherwise remain in full force and effect.

Contact Information

For questions about these Terms of Service or our services, please contact us: